M.L. MONTGOMERY, INC., AND M.L. MONTGOMERY, INDIVIDUALLY, APPELLANTS/CROSS APPELLEES,
v.
IAN AND JANET GRASSAM, APPELLEES/CROSS APPELLANTS

Fla. 4th DCA | 1991-06-05
No. 90-2243
GUNTHER and GARRETT, JJ., concur.
580 So. 2d 659 Florida District Court of Appeal, Fourth District (1991)

AI-generated. These summaries, headnotes, and key points are machine-generated and may contain errors or omissions. Always verify against the full opinion text below. Not legal advice.

Synopsis

A homeowner successfully sued a builder for breach of contract, negligence, and building code violations related to a failed house renovation project. The appellate court affirmed the judgment but modified the damages award by removing certain financing costs and remanding for prejudgment interest calculations.


Holding

The court affirmed the judgment finding breach of contract and negligence but reversed the award of $16,040.50 in closing costs for secondary financing because the project scope was enlarged with change orders not contemplated in the original contract, making it impossible to determine what portion of financing costs related to remedying the original default. The court also reversed and remanded to award prejudgment interest from the date of breach, excluding certain interest already paid.


Headnotes

[1] A builder's breach of contract, negligence, failure to supervise, and violation of building codes can support a judgment against them.

[2] Closing costs for new construction financing are not recoverable as damages when the project was enlarged by subsequent change orders and renovations not contemplated in…

Previewing 2 of 6 headnotes on this case. FLexlaw’s editorially structured points of law — every proposition, pinpointed — are reserved for members.

Join FLexlaw to unlock all legal intelligence

Key Quotes

“Without further discussion, we conclude that there is competent and substantial evidence in the record to support the trial judge's conclusion and we believe he also correctly followed the law laid down by our supreme court in Grossman Holdings Ltd. v. Hourihan, 414 So.2d 1037 (Fla.1982).”

Establishes the appellate court's affirmance of the trial court's findings on breach and negligence

Previewing 1 of 3 key quotes on this case — the court’s exact language, pinpointed for members.

Join FLexlaw to unlock all legal intelligence

Facts & Procedural History

M.L. Montgomery, Inc. was hired to perform extensive renovation work on a fifty-year-old house owned by Ian and Janet Grassam. The builder breached th…

The full statement of facts, procedural history, and disposition for this case are member content.

Join FLexlaw to unlock all legal intelligence

© FLexlaw, Inc. — AI-generated enrichments are proprietary. All rights reserved.


Opinion of the Court
LETTS, Judge.

LETTS, Judge.

After a bench trial, final judgment was entered in favor of the homeowners against a builder, the latter fired from a job involving extensive renovation of a fifty-year-old house. The trial court found the builder had breached his contract, had been negligent in his work, had failed to properly supervise the construction and had violated many applicable building codes. We affirm with one minor exception.

Without further discussion, we conclude that there is competent and substantial evidence in the record to support the trial judge’s conclusion and we believe he also correctly followed the law laid down by our supreme court in Grossman Holdings Ltd. v. Hourihan, 414 So. 2d 1037 (Fla.1982).

There is, however, one item of damages included in the final judgment with which we disagree. Namely, the “closing costs for new construction financing” of $16,040.50. These costs were incurred in securing secondary financing to enable completion of the renovation and effect redress for the builder’s substandard performance and default. It is not that we would never find such closing costs to be appropriate. On the contrary, see Nebraska Public Power District v. Austin Power, Inc., 773 F. 2d 960 (8th Cir.1985); Young v. Johnston, 475 So. 2d 1309, 1313 (Fla. 1st DCA 1985). However, they are not appropriate in the case at bar because the project was enlarged when the replacement contractor was hired to encompass further renovations and change orders not contemplated in the original contract upon which the builder defaulted. These change orders and further renovations inevitably increased the final cost and we are unable to determine from the record what portion of the additional financing, and the cost thereof, bore a direct relation to remedying the default under the original contract as distinct from additional renovations under the enlarged contract. We therefore conclude that the instant controversy is more compatible with a case out of this court which held that costs incurred, for additional improvements over and above those contemplated by the original contract, could not be considered when assessing damages. Georgia-Pacific Corp. v. Squires Development Corp., 387 So. 2d 986 (Fla. 4th DCA 1980).

We therefore reverse in part and remand for entry of an amended final judgment reducing the damages by $16,040.50. We find no merit in the other point on the main appeal.

Turning now to the cross appeal, we think the trial court erred in not awarding prejudgment interest. Such interest can be awarded in ex-contractu actions and, for the purpose of assessment thereof, a claim becomes liquidated and susceptible to prejudgment interest when the verdict has the effect of fixing damages as of a certain date. Argonaut Insurance Co. v. May Plumbing Co., 474 So. 2d 212 (Fla.1985). Argonaut is applicable here. However, as conceded at oral argument by the homeowner, “the interest [on the second mortgage] for period of delay attributable to defendants” in the sum of $8,637.00 does not permit of prejudgment interest under the facts of this case.

We therefore reverse and remand this cause for the entry of an amended final judgment awarding prejudgment interest from the date of the breach with the exception of the $8,637.00 referred to in the preceding paragraph. Needless to say, this calculation of prejudgment interest shall likewise exclude the $16,040.50 discussed earlier in this opinion.

AFFIRMED IN PART; REVERSED IN PART.

GUNTHER and GARRETT, JJ., concur.


Cases With Similar Vibessemantic neighbors from the corpus


Citator

Authorities Cited

Full citator, related cases, and AI research tools

Open in FLexlaw