PHILLIPS & JORDAN, INC., APPELLANT,
v.
STATE OF FLORIDA, DEPARTMENT OF TRANSPORTATION, APPELLEE

Fla. 1st DCA | 1992-06-23
No. 91-1614
SHIVERS, MINER and WOLF, JJ., concur.
602 So. 2d 1310 Florida District Court of Appeal, First District (1992) Caution
Cited by 6 cases

AI-generated. These summaries, headnotes, and key points are machine-generated and may contain errors or omissions. Always verify against the full opinion text below. Not legal advice.

Synopsis

Phillips & Jordan contracted to construct a fence and clear a 10-foot-wide strip along I-95, but cleared wider areas due to dense vegetation requiring 12-foot equipment. When denied payment for the excess acreage cleared, P&J sued, arguing the constructibility doctrine and unit price contract terms entitled it to compensation for work actually performed. The court affirmed summary judgment for DOT, holding the constructibility doctrine inapplicable where the contractor knew site conditions before bidding and had contractual procedures to seek reformation.


Holding

The court held that P&J is not entitled to additional compensation. The constructibility doctrine does not apply because P&J had pre-bid knowledge of site conditions and equipment requirements, so any need for wider clearing was not a latent defect. Although unit price contracts typically provide for payment of actual work performed, this contract contemplated only variable length, not width, and P&J was required to seek written contractual reformation before claiming payment for work outside specifications.


Headnotes

[1] The doctrine of constructibility does not apply when a contractor has knowledge of site conditions and the equipment to be used, and these facts indicate that the project…

[2] A contractor cannot claim a latent defect in job specifications when it had the opportunity to inspect the site, knew of site conditions, and knew that its chosen equipme…

Previewing 2 of 5 headnotes on this case. FLexlaw’s editorially structured points of law — every proposition, pinpointed — are reserved for members.

Join FLexlaw to unlock all legal intelligence

Key Quotes

“the constructibility doctrine (or the Spectrin doctrine) holds a hiring party liable for unanticipated construction costs incurred due to a latent defect in the project plans or specifications”

Defines the constructibility doctrine that P&J sought to invoke

Previewing 1 of 3 key quotes on this case — the court’s exact language, pinpointed for members.

Join FLexlaw to unlock all legal intelligence

Facts & Procedural History

P&J contracted with Florida DOT to construct a fence along approximately 71 miles of I-95 and clear a 10-foot-wide strip. The contract specified bidde…

The full statement of facts, procedural history, and disposition for this case are member content.

Join FLexlaw to unlock all legal intelligence

© FLexlaw, Inc. — AI-generated enrichments are proprietary. All rights reserved.


Opinion of the Court
PER CURIAM.

PER CURIAM.

Appellant Phillips and Jordan (P & J) and appellee Florida Department of Transportation (DOT) entered into a contract whereby P & J was to construct a fence along an estimated 71 miles of Interstate 1-95 in Brevard, County. The project plans also provided for the clearing and grubbing of a ten-foot-wide strip within which the fence was to be located. The standard bid form used by P & J to bid the contract specified that “all work is to be done in accordance with the plans, specifications, and special provisions of the State of Florida Department of Transportation.” The parties stipulated to the following pertinent facts: (1) the contract included provisions for clearing and grubbing work; (2) bidders were required to submit a unit price per acre for the clearing and grubbing; (3) the approximate amount of clearing and grubbing work was 179 acres; (4) the 179 acre estimate was derived by multiplying 10 feet times the estimated length of the project and converting the resulting square footage into acreage; (5) P & J submitted the lowest bid at $4,200.00 per acre for the clearing and grubbing work; (6) P & J satisfactorily completed the project; and (7) the contract did not specify the type or size of equipment to be used for the clearing and grubbing work.

Upon completion of the project, P & J hired a surveyor to verify the amount of fence erected and the number of acres cleared and grubbed. P & J then requested payment for the actual work performed by it at the unit prices bid. The actual length of the fence erected was slightly less than the project estimate. Accordingly, P & J was paid based on the price per unit. With respect to the clearing and grubbing work, P & J claimed that the density of the growth to be cleared made it necessary at times to use heavy duty clearing equipment with minimum twelve-foot-wide cutting blades. As a result, the area actually cleared, in some locations, exceeded the ten-foot width specified by the project plans. At completion of the project, according to P & J’s survey, the area actually cleared and grubbed measured 216.69 acres. DOT, however, refused to pay P & J for the acreage actually cleared. P & J filed suit claiming entitlement to payment for the work actually performed under the contract.

Appellee DOT filed a motion for summary judgment. A hearing on DOT’s motion was held on April 17, 1991. The trial court considered the pleadings, affidavits, depositions and arguments of the parties before granting DOT’s motion for summary judgment. Among the pertinent and undisputed facts adduced were the following. Before submitting its bid on the project, P & J sent its vice president, Benjamin R. Turner and assistant project manager, Kenneth A. Campbell, to view the project site by helicopter. Turner admitted that his observation of the site indicated that heavy equipment would be needed for portions of the clearing work because of the density of the growth to be cleared, and in order to achieve the minimum daily production necessary to meet the construction schedule. Turner also admitted that the equipment required for the job was equipped with minimum width blades of twelve feet, and was most likely owned by P & J prior to entering into the contract. In his deposition testimony, Turner stated although he had had discussions with DOT personnel regarding the clearing of an area in excess of ten feet wide, he could not recall if he was led to believe that he would be compensated for such clearing.

Mr. Campbell’s deposition testimony indicates that after informing DOT officials that it was necessary to clear more than a ten-foot width at times, the officials permitted such excessive clearing with instructions to keep the clearing to a minimum. No mention of additional compensation was made. Thereafter, Campbell had another meeting with DOT officials wherein he asked for additional compensation for areas cleared in excess of the ten-foot width. DOT officials informed Campbell that they did not agree with his interpretation of the contract under which he claimed payment due for the actual area cleared, rather than for a ten-foot wide area. Thus, DOT officials told Campbell that there would be no extra compensation for the area cleared in excess of ten feet. Campbell conceded that no DOT employee actually requested or directed him to clear an area in excess of ten feet wide.

On appeal, appellant relies first on the doctrine of constructibility to claim that the project could not be performed according to the plans and specifications provided, and that appellant is therefore entitled to compensation for the area actually cleared. Appellant also claims that the contract expressly provides for compensation for the area actually cleared. We find appellant’s arguments unpersuasive for the following reasons.

The doctrine of constructibility (or the Spectrin1 doctrine) holds a hiring party liable for unanticipated construction costs incurred due to a latent defect in the project plans or specifications. However, we find the constructibility doctrine to be inapplicable to the facts of the case at bar. Even assuming that the clearing and grubbing portion of the contract was inconstruc-tible as planned insofar as the equipment required was a minimum of twelve feet in width, such was not a latent defect in the job specifications. Appellant P & J had availed itself of the opportunity to inspect the job site, knew of the site conditions, knew of the type of equipment it would subsequently use at the site, and knew that its equipment of choice would clear an area in excess of ten feet in width. P & J submitted its bid in contemplation of these facts, and cannot now claim the existence of a latent defect in the job specifications such as would warrant the application of the implied warranty of constructibility.2

We are likewise unpersuaded by appellant’s argument that it is entitled to payment for the area actually cleared because the contract is a unit price contract predicated on payment for work actually performed. More precisely, the instant contract contemplates payment for work actually performed within the parameters of the job specifications. To be sure, a unit price contract provides for payment of the actual amount of work done or material supplied where the precise amounts needed are not known at the inception of the project. In the instant case, however, the only variable contemplated by the job specifications was the length of the area to be cleared and grubbed, not the width of such area. Furthermore, appellant was possessed of a contractual means to assert its claim for payment for work performed outside the specified ten-foot wide area. Appellant could have sought written authorization for payment for such work, in ef-feet, a reformation of the contract, under a contractual provision providing for such a reformation where it appears necessary. In fact, under the terms of the contract, appellant is precluded from seeking payment for work performed outside the contractual specifications without first seeking a written reformation of the contract. Therefore, appellant’s claim is barred by the express terms of the contract.

The material facts necessary to resolution of the instant case are not disputed. The trial court correctly granted summary final judgment in favor of appellee DOT.

AFFIRMED.

SHIVERS, MINER and WOLF, JJ., concur. . United States v. Spearin, 248 U.S. 132, 39 S.Ct. 59, 63 L.Ed. 166 (1918).

. Furthermore, we do not construe the trial court’s order to bar appellant’s claim under the doctrine of sovereign immunity because it is based on an implied covenant of the contract rather than an express term of the contract. Such a view would be erroneous. See Champagne-Webber, Inc. v. City of Fort Lauderdale, 519 So. 2d 696 (Fla. 4th DCA 1988). Rather, we construe the trial court’s order to bar appellant’s claim because it is outside both the express and implied conditions of the contract.


Cases With Similar Vibessemantic neighbors from the corpus


Citator

Cited By

  • Cnty. OF Brevard v. Miorelli Eng'g, Inc., 703 So. 2d 1049 (Fla. 1997)
    …with Southern Roadbuilders. Binding the sovereign to the implied covenants of an express contract is quite different from requiring a sovereign to pay for work not contemplated by that contract. See Phillips & Jordan, Inc. v. Department of Transp., 602 So. 2d 1310 (Fla. 1st DCA 1992) (distinguishing between a claim for breach of an implied covenant within an express contract and a claim outside both the express and implied conditions of the contract). Contrary to the court below, we conclude that the instant…
  • Cnty. of Brevard v. Miorelli Eng'g, Inc., 677 So. 2d 32 (Fla. 5th DCA 1996)
  • …concur. . The claims for overhead and office expenses were allegedly incurred due to the various delays in the construction process. . The First District noted Champagne-Webber with approval in Phillips & Jordan, Inc. v. Florida Dept. of Transp., 602 So. 2d 1310 (Fla. 1st DCA 1992).…

Previewing 3 of 4 citing cases — full citator treatment, depth of discussion, and citing context are member features.

Join FLexlaw to unlock all legal intelligence

Authorities Cited

Full citator, related cases, and AI research tools

Open in FLexlaw