MCDEVITT & STREET COMPANY, APPELLANT,
v.
DEPARTMENT OF GENERAL SERVICES, STATE OF FLORIDA, APPELLEE
AI-generated. These summaries, headnotes, and key points are machine-generated and may contain errors or omissions. Always verify against the full opinion text below. Not legal advice.
McDevitt & Street Company sought additional costs as general contractor for delays caused by the architect on a Florida International University building project. The court reversed the hearing officer's denial of excess direct labor cost damages and remanded for reconsideration under the proper legal standard, while affirming the denial of interest on borrowed capital.
The court held that the hearing officer's finding denying excess direct labor damages was not supported by competent, substantial evidence and remanded for the officer to determine: (1) whether the contractor's original labor estimate was reasonable; (2) whether actual expenditures were reasonable; and (3) whether any excess costs were attributable to the contractor or to the architect's delays. The court also held that if the contractor's evidence on total relevant costs is unrefuted, the 'total costs' method may be the proper measure of damages in breach of contract cases.
[1] A contractor may recover time-dependent costs incurred due to project delays caused by the owner's architect, calculated by multiplying the average daily cost by the numb…
[2] A contractor seeking recovery for excess direct labor costs must demonstrate the reasonableness of their original estimate, the reasonableness of actual expenditures, and…
Previewing 2 of 5 headnotes on this case. FLexlaw’s editorially structured points of law — every proposition, pinpointed — are reserved for members.
Join FLexlaw to unlock all legal intelligence“As in all breach of contract cases, the proper measure of damages ... is the amount of plaintiff's extra costs directly attributable to said breaches.”
Establishes the fundamental principle that damages must be directly attributable to the breach, which applies to the contractor's claims.
Previewing 1 of 3 key quotes on this case — the court’s exact language, pinpointed for members.
Join FLexlaw to unlock all legal intelligenceMcDevitt & Street Company was the general contractor for constructing the Student Services Building at Florida International University. The hearing o…
The full statement of facts, procedural history, and disposition for this case are member content.
Join FLexlaw to unlock all legal intelligence© FLexlaw, Inc. — AI-generated enrichments are proprietary. All rights reserved.
Explore caselaw by topic → Browse Delay Damages cases and more on FLexlaw
[*CCLXXII] ERVIN, Acting Chief Judge.
Appellant, McDevitt & Street Company, filed a claim with appellee, Department of General Services (DGS), for additional costs it had incurred as general contractor while constructing the Student Services Building at Florida International University. The hearing officer, whose recommended order and supplemental recommended order was adopted as the Department’s final order, found that actions and inactions of the architect had caused the project to be delayed 67 days past the contract completion date.
Appellant presented two exhibits at the hearing, along with expert testimony of a certified public accountant, to illustrate the damages which it sought. Exhibit 80, “Schedule of Total Job Site Supervisory, General and Administrative Costs”, was an accounting of all such time-dependent costs the contractor expended over the 501-day project. It stated that the costs ran at a daily average of $887.1 The hearing officer found that appellant was entitled to $59,-420, which was $887 times the 67 days the project was delayed. In this finding, the hearing officer stated that DGS was unable to refute the contractor’s determination, presented through its expert testimony, of average daily costs.
Appellant’s Exhibit 81, prepared and explained by the same experts, was entitled “Schedule of the Excess of Actual Direct Labor Costs over Estimate of Direct Labor Costs. . . .” Appellant argues that the hearing officer’s finding that it was not entitled to damages outlined in Exhibit 81 for additional direct labor costs was not based on competent, substantial evidence. The exhibit illustrated the difference between the sum appellant had budgeted for labor costs, in addition to the amounts given it in change orders for specific extra work, and the sum it had actually expended for direct labor costs: $144,770. The hearing officer’s supplemental recommended order found that all direct labor involved was covered by change orders which had extended the project time and the contract sum.
We agree that the finding was not based on competent, substantial evidence and remand to the hearing officer to determine whether appellant’s original estimate for direct labor costs was reasonable, whether the amounts it actually expended were reasonable and whether any excess direct labor costs were attributable to the appellant rather than to the delays caused by the Department’s architect. If the findings noted above are in appellant’s favor, then clearly it is due some remuneration for excess direct labor costs.
Appellant asserts it should be reimbursed for the total amount it expended above the sum of its estimate and the amounts paid it in change orders. “As in all breach of contract cases, the proper measure of damages ... is the amount of plaintiff’s extra costs directly attributable to said breaches.” J.
D. Hedin Construction Co. v. United States, 347 F. 2d 235, 259, 171 Ct.Cl. 70 (1965).
Appellant asserts that the amount of these excess labor costs directly attributable to appel-lee’s breach is impossible to pinpoint, but that the appellee’s fault is clearly established in the record. In federal government breach of contract cases, plaintiffs have been allowed to recover their “total costs” where it was shown the government was clearly at fault, where neither the accuracy of the contractor’s estimates nor the reasonableness of its expenditures was impugned, and where there was no alternative method of computing the damages. See Oliver-Finnie Company v. United States, 279 F. 2d 498, 150 Ct.Cl. 189 (1960); MacDougald Construction Company v. United States, 122 Ct.Cl. 210 (1952); Great Lakes Dredge and Dock Company v. United States, 96 F.Supp. 923, 119 Ct.Cl. 504 (1951). In J.
D. Hedin Construction Co. v. United States, supra, the court upheld an administrative determination that contract delays were attributable to the government and not to the contractor who sought delay damages. Explaining its award of “total costs” damages, the court stated:
[*CCLXXIII] The exact amount of additional work which plaintiff had to perform as a result of the foundation problem is difficult, if not impossible, to determine because of the nature of the corrective work which was being performed. The adverse weather conditions during the extended period in which the excavations remained open caused a myriad of problems. Additional trenching, form construction, and pumping of surface water became necessary. . . . There is no precise formula by which these additional costs can be computed and segregated from those costs which plaintiff would have incurred if there had been no government-caused difficulties.
However, the reasonableness and accuracy of plaintiff’s estimate, which was prepared by an experienced engineer whose qualifications have been unchallenged, have been established. Defense counsel stated that the estimate was not challenged. The closeness of the bids gives support to the reasonableness of the estimate. The bidders were three extremely experienced contractors of large construction projects. Plaintiff on prior occasions had successfully constructed a number of large projects for the Veterans Administration. Plaintiff has established the fact that it performed additional work.
Moreover, the responsibility of defendant for these damages is clear.
J. D. Hedin Construction Co., supra at 247.
In the more than 20 volumes of transcript before us, we have seen testimony concerning the appellant’s expertise in its field, including recitals of past successfully-completed projects, testimony of individuals who prepared appellant’s bid concerning their experience and their methods and testimony of appellant’s CPA firm explaining its theory of damages for both excess time-dependent and labor costs. It may be that no further testimony is needed; however, we are not the fact finders. If the hearing officer makes the relevant findings and if no alternative method of computing damages is given, then the “total costs” method may be the proper measure of dámages.
Appellant also argues that the hearing officer denied its claims for (1) increased interest on capital borrowed to finance the project; (2) 10% of its actual cost caused by the delays and change orders as additional profit and overhead, and, (3) an additional 1% of the added costs as an increased bond cost. The parties’ contract under the “Changes in the Work” article, allowed the excess profit, overhead and bond costs. If, as it appears, the contractor’s evidence on its total, relevant costs is unrefuted in the record, including evidence of its excess direct labor costs, the hearing officer should bind appellee to its agreement and assess the costs as described in the contract. The finding that appellant was not entitled to its interest on borrowed capital during the delay is based on competent, substantial evidence and will not be disturbed in this appeal.
We affirm the hearing officer’s finding, which we determine was based upon competent and substantial evidence, that delay damages would be based upon the parties’ contract completion date.
By reason of the cause’s disposition as stated in this opinion, it is unnecessary to rule upon the propriety of appellant’s motion to strike portions of appellee’s brief. Reversed and remanded for further proceedings consistent with this opinion.
MELVIN, J., and MASON, ERNEST E., Associate Judge, concur. . Exhibit 80 originally stated that the daily average of those time dependent costs was $939. However, that figure was modified later at the hearing and in another exhibit.
Cases With Similar Vibessemantic neighbors from the corpus
Citator
Cited By
-
Dep't OF Transp. v. Hawkins Bridge Co., 457 So. 2d 525 (Fla. 1st DCA 1984)…s no other practicable means of measuring damages, the original bid was realistic, the actual costs were reasonable, and the plaintiff is not responsible for any of the additional expense. McDevitt & Street Company v. Department of General Services, 377 So. 2d 191 (Fla. 1st DCA 1979). We find sufficient record evidence to support satisfaction of these four criteria here. For example, the record fully supports a finding that there was no practicable means of measuring damages other than the total cost method i…
-
Perma Builders, Inc. v. JBM Assocs., Inc., 472 So. 2d 1381 (Fla. 4th DCA 1985)…ved. Id. We cannot set aside a damage award in a breach of contract action because we might disagree with the amount or because we might have ruled differently on the same proof. Id.; see also McDevitt & Street Co. v. Department of General Services, 377 So. 2d 191 (Fla. 1st DCA 1979). The determination of the amount of costs incurred by JBM was a question of fact, and the trial court’s resolution of that question comes to us clothed with a presumption of correctness. E.g., Industrial Builders, Inc. v. Heritag…
-
Roberts & Schaefer Co. v. Hardaway Co., 152 F.3d 1283 (11th Cir. 1998)…these damages. . The total-cost method provides compensation for the total amount the sub-contractor expended above the sum of its estimate and the amounts paid the sub-contractor in change orders. McDevitt & Street Co. v. Department of Gen. Servs., 377 So. 2d 191, 192 (Fla.Dist.Ct.App.1979).…
Authorities Cited
- J. D. Hedin Constr. Co., Inc. v. The United States, 347 F.2d 235 (Ct. Cl. 1965)
- Oliver-Finnie Co. v. United States, 279 F.2d 498 (Ct. Cl. 1960)