ELIZABETH REITANO, A/K/A ELIZABETH REITANO SPURLOCK, APPELLANT,
v.
PENINSULAR BUILDING SUPPLY COMPANY, A FLORIDA CORPORATION, APPELLEE

Fla. 2d DCA | 1972-05-24
No. 71-427
McNULTY, J„ and BEASLEY, THOMAS D., Associate Judge, concur.
262 So. 2d 710 Florida District Court of Appeal, Second District (1972) Positive Treatment
Cited by 8 cases

AI-generated. These summaries, headnotes, and key points are machine-generated and may contain errors or omissions. Always verify against the full opinion text below. Not legal advice.

Synopsis

This case involves a mechanic's lien foreclosure action where a roofing contractor (Peninsular) sued to recover payment for roof repair work, and the homeowner (Reitano) counterclaimed for breach of contract and negligent construction after water damage occurred while her house was left uncovered. The appellate court affirmed the trial court's judgment granting foreclosure and denying the counterclaim, finding insufficient evidence of damages causally attributable to the contractor.


Holding

The trial court properly denied Reitano's counterclaim because she failed to present sufficient competent evidence to establish the cause and extent of damages attributable to Peninsular, and the trial court properly excluded her itemized cost statements because they were made after months of additional exposure to the elements and thus did not reflect the cost of immediate repairs.


Headnotes

[1] A party seeking to recover damages for breach of contract must provide a reasonable basis for computation, even if the result is only approximate.

[2] Uncertainty regarding the cause of damage, rather than the amount, defeats recovery.

Previewing 2 of 6 headnotes on this case. FLexlaw’s editorially structured points of law — every proposition, pinpointed — are reserved for members.

Join FLexlaw to unlock all legal intelligence

Key Quotes

“The uncertainty which defeats recovery in such cases has reference to the cause of the damage rather than to the amount of it. If from proximate estimates of witnesses a satisfactory conclusion can be reached, it is sufficient if there is such certainty as satisfies the mind of a prudent and impartial person.”

Establishes the legal standard that uncertainty as to the cause of damage (rather than amount) prevents recovery; also describes the proper test for sufficiency of damages evidence.

Previewing 1 of 3 key quotes on this case — the court’s exact language, pinpointed for members.

Join FLexlaw to unlock all legal intelligence

Facts & Procedural History

Reitano contracted with Peninsular to repair her roof and paid an initial $1,500. Peninsular removed the old roof, ceiling, fixtures, and electrical w…

The full statement of facts, procedural history, and disposition for this case are member content.

Join FLexlaw to unlock all legal intelligence

© FLexlaw, Inc. — AI-generated enrichments are proprietary. All rights reserved.


Opinion of the Court
PIERCE, Chief Judge.

*711PIERCE, Chief Judge.

Appellant Elizabeth Reitano, a/k/a Elizabeth Reitano Spurlock, appeals a final judgment granting foreclosure of the mechanic’s lien filed by appellee Peninsular Building Supply Company, and denying Reitano’s counterclaim.

Reitano and Peninsular had entered into a contract to repair the roof on Reitano’s house. Reitano made the initial payment of $1,500.00 and shortly thereafter Peninsular removed the old roof, ceiling, fixtures, and electrical wiring from the house. The property was left uncovered for over a week, during which time it rained. At Reitano’s request, Peninsular’s agents covered the house with Visqueen plastic in order to protect it from water damage.

After the framing and sheathing had been completed, Peninsular’s President presented Reitano with a bill for the second payment called for under the contract, and Reitano informed him that she would make no further payments under the contract until she talked with her attorney on the basis that her property had been damaged by a rainstorm while it was uncovered. Peninsular took its men off the job on January 2, 1970. Reitano permitted her property to remain in this condition for several months.

Peninsular filed its complaint seeking to foreclose a mechanic’s lien. Reitano filed her counterclaim alleging breach of contract and negligent construction of the improvements.

Peninsular’s President testified that the cost to finish the job was $475.00. Reitano introduced two estimates from another contractor of the cost to complete the work, repair the water damage, and do some additional work, but the contractor could not determine the cost of repairs for water damage to any individual item and was unable to specify the costs attributable to contract and non-contract items. Rei-tano elected to complete the repairs herself and did not engage the services of the contractor. She also attempted to introduce into evidence the exact dollar amount of the cost she incurred in repairing the damaged property and in completing the repair work, but the trial Court refused to accept this evidence without a predicate of expert testimony that the bills were comparable on prices for the items and labor. The Court also stated that the denial was predicated upon the fact that Reitano had already admitted other evidence of the cost of completing the contract. Reitano testified that the water damage to the furniture and furnishings amounted to $1,195.00.

There was conflicting testimony as to the extent of the repairs agreed upon. Reitano contends that the contract did not call for the removal of the ceiling and electrical wiring, while Peninsular maintains that this was discussed before the contract was prepared and that the removal of such items was necessary in order to repair the roof as agreed upon.

The trial Judge made specific findings that the allegations contained in the complaint had been proven by competent evidence. He also denied Reitano’s counterclaim, finding that some damage had occurred to her property as a result of Peninsular’s actions, but that there was insufficient competent and substantial evidence to ascertain the extent of said damages without speculation. He further found that the principal amount of the lien was $2,191.00, awarded Peninsular court costs in the amount of $147.20, and attorney’s fee in the amount of $1,000.00, and allowed foreclosure.

Uncertainty as to the amount of the damage will not prevent recovery. It is sufficient that there be a reasonable basis of computation although the result may be only approximate. McCall v. Sherbill, Fla.1953, 68 So.2d 362. As stated in Twyman v. Roell, 1936, 123 Fla. 2, 166 So. 215, 218:

“The uncertainty which defeats recovery in such cases has reference to the cause *712of the damage rather than to the amount of it. If from proximate estimates of witnesses a satisfactory conclusion can be reached, it is sufficient if there is such certainty as satisfies the mind of a prudent and impartial person (citation omitted).”

In the case sub judice there was uncertainty as to the cause of the damage. Reitano testified that she discovered water damage to her property after Peninsular took its men off the job, but Peninsular contradicted this testimony, stating that after the rain the condition of the property was substantially the same as it was before the rain. The estimates introduced into evidence by Reitano did not show that the proposed work was necessary or related to water damage, and the person who made the estimate, dated January 8, 1970, testified on cross-examination that he could not say what the status of the water condition was as of that date. Reitano permitted the property as well as the furnishings to remain exposed to the elements for months after January 2, 1970. The house was old and the roof leaked prior to the date of the contract. There was no yardstick for determining how much of the damages to the house or the furnishings could be attributable to Peninsular, nor was there a reasonable basis of computing the damages. Equitable Fire & M. Ins. Co. v. Tiernan Building Corp., Fla.App.1966, 190 So.2d 197, and cases cited. Cf. McCall, supra; Twyman, supra.

Reitano claims that she should have been permitted to introduce into evidence the itemized statements for labor and materials paid by her to complete the contract and repair the water damage to her property. She cites R. K. Cooper Builders, Inc. v. Free-Lock Ceilings, Inc., Fla.App.1969, 219 So.2d 87, for the rule that the proper measure of damages for failure to complete work provided in the contract is the actual expenditures, made in good faith, that are necessary to complete the job. But this rule does not apply where the owner terminates the contract without a legally sufficient reason therefor or prevents the contractor from completing the contract. In such situations the measure of damages is generally the reasonable cost of making the work performed conform to the contract. Ray v. Dock and Marine Construction, Inc., Fla.App.1966, 183 So.2d 237; 17A C.J.S. Contracts §§ 469 and 512; 25 C.J.S. Damages § 75. Also, the repairs for the water damage were made after the property had remained exposed to the elements many months, and the cost of these repairs would not have reflected the cost of repairing the damage immediately after the contract was terminated.

The testimony as to whether the contract called for removing the ceiling and electrical wiring, and also the amount required to complete the contract was in conflict. Absent a showing that the Court’s finding was unsupported by sufficient evidence, this Court will not disturb the finding of the lower Court. Cormier v. Williams, 1941, 148 Fla. 201, 4 So.2d 525; Clausi v. Casner Motors, Fla.App.1959, 112 So.2d 587.

Neither do we find that the Court erred in awarding Peninsular an attorney’s fee of $1,000.00. Reitano has failed to show that the same was unreasonable or excessive.

Affirmed.

McNULTY, J„ and BEASLEY, THOMAS D., Associate Judge, concur.


Cases With Similar Vibessemantic neighbors from the corpus


Citator

Cited By

  • Sampley Enters., Inc. v. Laurilla, 404 So. 2d 841 (Fla. 5th DCA 1981)
    …ascertainment with only a reasonable degree of certainty. Mori. This test is satisfied if there is a reasonable basis in the evidence for computation of damages, although the result may be only approximate. Reitano v. Peninsular Building Supply Co., 262 So. 2d 710 (Fla. 2d DCA 1972); 17 Fla.Jur.2d, Damages, § 18 (1980). Profit may be established by subtracting from the contract price the total cost and expenses of labor, services and materials necessary for the non-breaching party to complete the contract. T…
  • …logous, though it deals with completion rather than repair, as plaintiff here is claiming his measure of the damages is proper. He may be wrong, but we have been shown no circumstance in mitigation of his claim. Bee Reitano v. Peninsular Supply Co., 262 So. 2d 710 (2d D.C.A.Fla.1972). . The Oiminelli court then used the repair cost as evidence of the building value before and after repair. It appears the measure should have been the cost of reasonable repair. See McCormick on Damages, § 168 Defective Constru…
  • Meece v. Hogue, 334 So. 2d 285 (Fla. 2d DCA 1976)
    …where there is uncertainty as to at which of several points in time damage occurred, there is “no yardstick” for determining how much of the damage is attributable to the acts of each party. See Reitano v. Peninsular Building Supply Co., Fla.App.2d, 262 So. 2d 710. In the situation presented here, we hold that appellants are not liable for damage which resulted to the house after a reasonable time following the discovery of the termites. The appellee has the burden of proving his cause of action by showing hi…

Previewing 3 of 4 citing cases — full citator treatment, depth of discussion, and citing context are member features.

Join FLexlaw to unlock all legal intelligence

Authorities Cited

Full citator, related cases, and AI research tools

Open in FLexlaw